3.2 Schedule of Performance.
Contractor shall commence the services pursuant to this Agreement upon receipt of a
written notice to proceed and shall perform all services within the time period(s) established by the
3.3 Force Majeure.
The time period(s) specified in the Schedule of Performance for performance of the
services rendered pursuant to this Agreement shall be extended because of any delays due to
unforeseeable causes beyond the control and without the fault or negligence of the Contractor,
including, but not restricted to, acts of God or of the public enemy, unusually severe weather, fires,
earthquakes, floods, epidemics, quarantine restrictions, riots, strikes, freight embargoes, wars, litigation,
and/or acts of any governmental agency, including ATN, if the Contractor shall within ten (10) days of
the commencement of such delay notify the Contract Officer in writing of the causes of the delay. The
Contract Officer shall ascertain the facts and the extent of delay, and extend the time for performing the
services for the period of the enforced delay when and if in the judgment of the Contract Officer such
delay is justified. The Contract Officer’s determination shall be final and conclusive upon the parties to
this Agreement. In no event shall Contractor be entitled to recover damages against ATN for any delay
in the performance of this Agreement, however caused, Contractor’s sole remedy being extension of the
Agreement pursuant to this Section.
Unless earlier terminated in accordance with Section 7.8 of this Agreement, this
Agreement shall continue in full force and effect until completion of the services but not exceeding one
(1) year from the date hereof, except as otherwise provided in the Schedule of Performance.
4.0 COORDINATION OF WORK
4.1 Representative of Contractor.
The following principals of Contractor are hereby designated as being the principals and
representatives of Contractor authorized to act in its behalf with respect to the work specified herein
and make all decisions in connection therewith:
It is expressly understood that the experience, knowledge, capability and reputation of the foregoing
principals were a substantial inducement for ATN to enter into this Agreement. Therefore, the
foregoing principals shall be responsible during the term of this Agreement for directing all activities of
Contractor and devoting sufficient time to personally supervise the services hereunder. For purposes of